Tenderdocnit10
Tenderdocnit10
_____________________________ Department
Appendix 2.10
Tender Document
Page 1 of 78
Appendix 2.10
Tender Document
Table of Contents
Annexure -A to M 15 - 37
Table of Clauses 38
Part - I General Conditions of 39 - 56
Contract (GCC)
Section 3 Contract Data 57 - 59
Annexure - N to W 60 - 75
Page 2 of 78
SECTION 1
Notice Inviting e-Tenders
Government of Madhya Pradesh
_____________________ Department
N.I.T. No __________________/e-tendering dated ___________
Online percentage rate bids for the following works are invited from registered
contractors and firms of repute fulfilling registration criteria:
Section 1 – NIT
Page 3 of 78
Notice Inviting Tender
Government of Madhya Pradesh
_____________________ Department
Office of the _________________________
_________________________________________
Online percentage rate bids for the following works are invited from registered
contractors and firms of repute fulfilling registration criteria:
S. No. Name District(s) Probable Earnest Cost of Bid Category Period of
/Pkg/ of Work Amount of Money Document of Completion
Code Contract Deposit (EMD) (In Rupees) Contractor (in Months)
(Rs. in lakh) (In Rupees)
1. All details relating to the Bid Document(s) can be viewed and downloaded free of
cost on the website.
2. Bid Document can be purchased after making online payment of portal fees
through Credit/Debit/Cash Card/internet banking.
3. At the time of submission of the Bid the eligible bidder shall be required to:
i) pay the cost of Bid Document;
ii) deposit the Earnest Money;
iii) Submit a check list; and
iv) Submit an affidavit.
Details can be seen in the Bid Data Sheet.
4. ELIGIBILITY FOR BIDDERS:
(a) At the time of submission of the Bid the bidder should have valid registration
with the Government of Madhya Pradesh, PWD in appropriate class. However,
such bidders who are not registered with the Government of Madhya Pradesh
Section 1 – NIT
Page 4 of 78
and are eligible for registration can also submit their bids after having applied
for registration with appropriate authority.
(b) The bidder would be required to have valid registration at the time of signing of
the Contract.
(c) Failure to sign the contract by the selected bidder, for whatsoever reason, shall
result in forfeiture of the earnest money deposit.
6. Special Eligibility - Special Eligibility Conditions, if any, are given in the Bid Data
Sheet.
7. The Bid Document can be purchased only online from __________ (time) _________
(date) to __________ (time) __________ (date). Other key dates may be seen in
bid data sheet.
Section 1 – NIT
Page 5 of 78
SECTION 2
INSTRUCTIONS TO BIDDERS (ITB)
A. GENERAL
1. SCOPE OF BID
The detailed description of work, hereinafter referred as ‘work’, is given in the Bid
Data Sheet.
2. General Quality of Work:
The work shall have to be executed in accordance with the technical specifications
specified in the Bid Data sheet/ Contract Data, and shall have to meet high
standards of workmanship, safety and security of workmen and works.
3. PROCEDURE FOR PARTICIPATION IN E-TENDERING
The procedure for participation in e-tendering is given in the Bid Data Sheet.
4. ONE BID PER BIDDER
4.1 The bidder can be an individual entity or a joint venture (if permitted as per Bid
Data Sheet). In case the J.V. is permitted, the requirement of joint venture shall be
as per the Bid Data Sheet.
4.2 No bidder shall be entitled to submit more than one bid whether jointly or severally. If
he does so, all bids wherein the bidder has participated shall stand disqualified.
5. Cost of Bidding
The bidder shall bear all costs associated with the preparation and submission of
his bid, and no claim whatsoever for the same shall lie on the Government.
6. Site Visit and examination of works
The bidder is advised to visit and inspect the Site of Works and its surroundings and
obtain for itself on its own responsibility all information that may be necessary for
preparing the bid and entering into a contract for construction of the work. All
costs in this respect shall have to be borne by the bidder.
B. Bid Documents
7. CONTENT OF BID DOCUMENTS
The Bid Document comprises of the following documents:
Page 6 of 78
2. Instructions to Bidders, Bid Data Sheet with all Annexures
3. Conditions of Contract:
i. Part I General Conditions of Contract and the Contract Data with all
Annexures; and
ii. Part II Special Conditions of Contract.
4. Specifications
5. Drawings
6. Priced Bill of Quantities
7. Technical and Financial Bid
8. Letter of Acceptance
9. Agreement, and
10. Any other document(s), as specified.
8. The bidder is expected to examine carefully all instructions, conditions of contract,
the contract data, forms, terms and specifications, bill of quantities, forms and
drawings in the Bid Document. Bidder shall be solely responsible for his failure to
do so.
9. Pre-Bid Meeting (where applicable)
Wherever the Bid Data Sheet provides for pre-bid meeting:
9.1 Details of venue, date and time would be mentioned in the Bid Data Sheet.
Any change in the schedule of pre-bid meeting would be communicated on
the website only, and intimation to bidders would not be given separately.
9.2 Any prospective bidder may raise his queries and/or seek clarifications in
writing before or during the pre-bid meeting. The purpose of such meeting
is to clarify issues and answer questions on any matter that may be raised at
that stage. The Employer may, at his option, give such clarifications as are
felt necessary.
9.3 Minutes of the pre-bid meeting including the gist of the questions raised
and the responses given together with any response prepared after the
meeting will be hosted on the website.
Page 7 of 78
10. Amendment of Bid Documents
10.1 Before the deadline for submission of bids, the Employer may amend or
modify the Bid Documents by publication of the same on the website.
10.2 All amendments shall form part of the Bid Document.
10.3 The Employer may, at its discretion, extend the last date for submission of
bids by publication of the same on the website.
C. Preparation of Bid
11. The bidders have to prepare their bids online, encrypt their Bid Data in the Bid
Forms and submit Bid Seals (Hashes) of all the envelopes and documents related to
the Bid required to be uploaded as per the time schedule mentioned in the key
dates of the Notice Inviting e-Tenders after signing of the same by the Digital
Signature of their authorized representative.
12. DOCUMENTS COMPRISING THE BID
The bid submitted online by the bidder shall be in the following parts:
Part 1 – This shall be known as Online Envelope A and would apply for all bids.
Online Envelop A shall contain the following as per details given in the Bid Data
Sheet:
i) Registration number or proof of application for registration and
organizational details in format given in the Bid Data Sheet.
ii) Payment of the cost of Bid Document;
iii) Earnest Money; and
iv) An affidavit duly notarized.
Part 2 – This shall be known as Online Envelope B and required to be submitted only
in works where pre-qualification conditions and/or special eligibility conditions are
stipulated in the Bid Data Sheet. Online Envelop B shall contain a self-certified sheet
duly supported by documents to demonstrate fulfillment of pre-qualification
conditions.
Part 3 – This shall be known as Online Envelope C and would apply to all bids.
Envelop C shall contain financial offer in the prescribed format enclosed with the
Bid Data Sheet.
13. Language
The bid as well as all correspondence and documents relating to the bid exchanged
by the Bidder and the Employer shall be in English or Hindi. Supporting documents
and printed literature that are part of the Bid may be in another language provided
they are accompanied by an accurate translation of the relevant passages in
English. In such case, for the purposes of interpretation of the bid, such translation
shall govern.
Page 8 of 78
14. TECHNICAL PROPOSAL
14.1 Only, in case of bids with pre-qualification conditions defined in the Bid Data
Sheet, the Technical Proposal shall comprise of formats and requirements
given in the Bid Data Sheet.
14.2 All the documents/ information enclosed with the Technical Proposal should
be self-attested and certified by the bidder. The Bidder shall be liable for
forfeiture of his earnest money deposit, if any document / information are
found false/ fake/ untrue before acceptance of bid. If it is found after
acceptance of the bid, the bid sanctioning authority may at his discretion
forfeit his performance security/ guarantee, security deposit, enlistment
deposit and take any other suitable action.
15. FINANCIAL BID
i. The bidder shall have to quote rates in format referred in Bid Data Sheet, in
overall percentage, and not item wise. If the bid is in absolute amount, overall
percentage would be arrived at in relation to the probable amount of contract
given in NIT. The overall percentage rate would apply for all items of work.
ii. Percentage shall be quoted in figures as well as in words. If any difference in
figures and words is found, lower of the two shall be taken as valid and correct.
iii. The bidder shall have to quote rates inclusive of all duties, taxes, royalties and
other levies; and the Employer shall not be liable for the same.
iv. The material along with the units and rates, which shall be issued, if any, by
the department to the contractor, is mentioned in the Bid Data Sheet.
16. PERIOD OF VALIDITY OF BIDS
The bids shall remain valid for a period specified in the Bid Data Sheet after the date
of “close for biding” as prescribed by the Employer. The validity of the bid can be
extended by mutual consent in writing.
17. EARNEST MONEY DEPOSIT (EMD)
17.1 The Bidder shall furnish, as part of the Bid, Earnest Money Deposit (EMD), in
the amount specified in the Bid Data Sheet.
17.2 The EMD shall be in the form of Fixed Deposit Receipt of a scheduled
commercial bank, issued in favour of the name given in the Bid Data Sheet.
The Fixed Deposit Receipt shall be valid for six months or more after the last
date of receipt of bids. However, other form(s) of EMD may be allowed by
the Employer by mentioning it in the Bid Data Sheet.
Page 9 of 78
17.3 Bid not accompanied by EMD shall be liable for rejection as non-responsive.
17.4 EMD of bidders whose bids are not accepted will be returned within ten
working days of the decision on the bid.
17.5 EMD of the successful Bidder will be discharged when the Bidder has signed
the Agreement after furnishing the required Performance Security.
17.6 Failure to sign the contract by the selected bidder, within the specified
period, for whatsoever reason, shall result in forfeiture of the earnest
money deposit.
D. Submission of Bid
18. The bidder is required to submit online bid duly signed digitally, and Envelop ‘A’ in
physical form also at the place prescribed in the Bid Data Sheet.
19.1 Envelope ‘A’ shall be opened first online at the time and date notified and
its contents shall be checked. In cases where Envelop ‘A’ does not contain all
requisite documents, such bid shall be treated as non-responsive, and
Envelop B and/or C of such bid shall not be opened.
19.2 Wherever Envelop ‘B’ (Technical Bid) is required to be submitted, the same
shall be opened online at the time and date notified. The bidder shall have
freedom to witness opening of the Envelop ‘B’. Envelop ‘C’ (Financial Bid) of
bidders who are not qualified in Technical Bid (Envelop ‘B’) shall not be
opened.
19.3 Envelope ‘C’ (Financial Bid) shall be opened online at the time and date notified.
The bidder shall have freedom to witness opening of the Envelop ‘C’.
19.4 After opening Envelop ‘C’ all responsive bids shall be compared to
determine the lowest evaluated bid.
19.5 The Employer reserves the right to accept or reject any bid, and to annul the
bidding process and reject all the bids at any time prior to contract award,
without incurring any liability. In all such cases reasons shall be recorded.
19.6 The Employer reserves the right of accepting the bid for the whole work or
for a distinct part of it.
Page 10 of 78
20. Confidentiality
20.2 Any attempt by a bidder to influence the Employer in the evaluation of the
bids or contract award decisions may result in the rejection of his bid.
F. Award of Contract
21. Award of Contract
The Employer shall notify the successful bidder by issuing a ‘Letter of Acceptance’
(LOA) that his bid has been accepted.
22. Performance Security
22.1 Prior to signing of the Contract the bidder to whom LOA has been issued
shall have to furnish performance security of the amount in the form and for
the duration, etc. as specified in the Bid Data Sheet.
22.2 Additional performance security, if applicable, is mentioned in the Bid Data
Sheet and shall be in the form and for the duration, etc. similar to
Performance Security.
23. Signing of Contract Agreement
23.1 The successful bidder shall have to furnish Performance Security and
Additional Performance Security, if any, and sign the contract agreement
within 15 days of issue of LOA.
Page 11 of 78
24. CORRUPT PRACTICES
The Employer requires that bidders observe the highest standard of ethics during the
procurement and execution of contracts. In pursuance of this policy, the Employer:
i. may reject the bid for award if it determines that the bidder recommended
for award has, directly or through an agent, engaged in corrupt, fraudulent,
collusive, or coercive practices in competing for the Contract; and
ii. may debar the bidder declaring ineligible, either indefinitely or for a stated
period of time, to participate in bids, if it at any time determines that the
bidder has, directly or through an agent, engaged in corrupt, fraudulent,
collusive, or coercive practices in competing for, or in executing, a contract.
For the purposes of this provision, the terms set forth above are defined as
follows:
Page 12 of 78
Bid Data Sheet
GENERAL
SR. No. PARTICULARS DATA
1 Office inviting tender
2 NIT No
3 Date of NIT
4 Bid document download available
from date & time
5 Website link http:// www……………..
SECTION 1 - NIT
CLAUSE
PARTICULARS DATA
REFERENC
E
2 Portal fees Rs.
3 Cost of bid document Rs.
Cost of bid document Payable at --------------------------------------------
--------------------------------------------
Cost of bid document In favor of --------------------------------------------
--------------------------------------------
4 Affidavit format Annexure B
5 Pre-qualifications required
If Yes, details Annexure C
6 Special Eligibility
If Yes, details Annexure D
7 Key dates Annexure A
SECTION 2 - ITB
CLAUSE
PARTICULARS DATA
REFERENCE
1 Name of ‘work’ …………………………………………………..
…………………………………………………..
…………………………………………………..
2 Specifications Annexure – E
3 Procedure for participation in e- Annexure – F
tendering
Whether Joint Venture is allowed NO
4
Pre bid meeting to be held
If Yes, Date, Time & Place Date :-----------
9
Time from:
Place:-----------
Page 13 of 78
Bid Data Sheet
CLAUSE
PARTICULARS DATA
REFERENCE
Envelope-A containing : At the Office of the ------------------
i. Registration number or proof of --------------------------------------------
application for registration and --------------------------------------------
organizational details as per --------------------------------------------
12 Annexure H --------------------------------------------
ii. Cost of Bid Document --------------------------------------------
iii. EMD
iv. An affidavit duly notarized as
per Annexure - B Before --------------- (date)
should reach in physical form
14 Envelope-B Technical Proposal Annexure - I and
Annexure - I (Format I-1 to I-5)
Envelope-C Financial Bid Annexure - J
15 Materials to be issued by the Annexure - K
department
120 Days from the date of
16 Period of Validity of Bid submission of tender
12
Performance security valid up to Valid Contract period plus 3
months
Page 14 of 78
Annexure – A
(See clause 1, 7 of Section 1 -NIT )
KEY DATES
Purchase of Tender
– Online
2 -
Bid Submission
–Online
Open (Envelope- A)
( PQ Envelope- B)
(Envelope-C)
Original term deposit receipt of earnest money deposit, demand draft for the cost of bid
document and affidavit shall be submitted by the bidder so as to reach the office as
prescribed in Bid Data Sheet, at least one calendar day before specified start time and date
in key dates for opening of technical proposal as per Key dates in Bid Data Sheet.
Section 2 –Annexure - A
Page 15 of 78
Annexure – B
(See clause 3 of Section 1 -NIT )
|| AFFIDAVIT ||
(To be Contained in Envelope A)
(On Non Judicial Stamp of Rs. 100)
I/we _______________________________________________________ who is/ are
_______________________ (status in the firm/ company) and competent for submission
of the affidavit on behalf of M/S ______________________ (contractor) do solemnly
affirm an oath and state that:
I/we am/are fully satisfied for the correctness of the certificates/records submitted
in support of the following information in bid documents which are being submitted in
response to notice inviting e-tender No. ______________ for
__________________________ (name of work) dated _______ issued by the
________________ (name of the department).
I/we am/ are fully responsible for the correctness of following self-certified
information/ documents and certificates:
1. That the self-certified information given in the bid document is fully true and
authentic.
2. That:
a. Term deposit receipt deposited as earnest money, demand draft for cost of bid
document and other relevant documents provided by the Bank are authentic.
b. Information regarding financial qualification and annual turnover is correct.
c. Information regarding various technical qualifications is correct.
3. No close relative of the undersigned and our firm/company is working in the
department.
OR
Following close relatives are working in the department:
Name _______________ Post ____________________ Present Posting ___________
Section 2 –Annexure - B
Page 16 of 78
Annexure – D
(See clause 6 of Section 1 -NIT )
SPECIAL ELIGIBILITY CRITERIA
Section 2 –Annexure - D
Page 18 of 78
Annexure -F
(See clause 3 of section 2-ITB)
2. Digital Certificate:
The bids submitted online should be signed electronically with a Class III
Digital Certificate to establish the identity of the bidder submitting the bid
online. The bidders may obtain Class III Digital Certificate issued by an
approved Certifying Authority authorized by the Controller of Certifying
Authorities, Government of India. A Class III Digital Certificate is issued upon
receipt of mandatory identity proofs along with an application. Only upon the
receipt of the required documents, a Digital Certificate can be issued. For
details please visit cca.gov.in.
Note:
i. It may take upto 7 working days for issuance of Class III Digital
Certificate; hence the bidders are advised to obtain the certificate at
the earliest. Those bidders who already have valid Class III Digital
Certificate need not obtain another Digital Certificate for the same.
The bidders may obtain more information and the Application From
required to be submitted for the issuance of Digital Certificate from
CCA.GOV.IN
ii. Bids can be submitted till bid submission end date. Bidder will require
digital signature while bid submission.
Section 2 –Annexure - F
Page 23 of 78
`
The digital certificate issued to the Authorized User of a Partnership firm /
Private Limited Company / Public Limited Company and used for online
biding will be considered as equivalent to a no-objection certificate / power of
attorney to that user.
4. Key Dates:
The bidders are strictly advised to follow the time schedule (Key Dates) of the
bid on their side for tasks and responsibilities to participate in the bid, as all the
stages of each bid are locked before the start time and date and after the end
time and date for the relevant stage of the bid as set by the Department.
Section 2 –Annexure - F
Page 24 of 78
5. Preparation and Submission of Bids
The bidders have to prepare their bids online, encrypt their bid Data in the
Bid forms and submit Bid of all the envelopes and documents related to the
Bid required to be uploaded as per the time schedule mentioned in the key
dates of the Notice inviting e-Tenders after signing of the same by the Digital
Signature of their authorized representative.
Section 2 –Annexure - F
Page 25 of 78
Annexure – G
(See clause 4 of Section 2 -ITB)
Section 2 –Annexure - G
Page 26 of 78
Annexure - H
(See clause 12 of Section 2 –ITB & clause 4 of GCC)
ORGANIZATIONAL DETAILS
(To be Contained in Envelope - A)
S.
Particulars Details
No.
Registration number issued by Centralized
1. Registration System of Govt. of M.P. or Proof of (If applicable, scanned copy of proof of
application for registration.
application for registration to be uploaded)
Registration No. _________ Date______
Valid Registration of bidder in appropriate class
2. (Scanned copy of Registration to be
through Centralized Registration of Govt. of MP
uploaded)
Name of Organization/ Individual/ Proprietary
3.
Firm/ Partnership Firm
Entity of Organization
Individual/ Proprietary Firm/ Partnership Firm
4. (Registered under Partnership Act)/ Limited
Company (Registered under the Companies
Act–1956)/ Corporation/ Joint Venture
5. Address of Communication
6. Telephone Number with STD Code
7. Fax Number with STD Code
8. Mobile Number
9. E-mail Address for all communications
Details of Authorized Representative
10. Name
11. Designation
12. Postal Address
13. Telephone Number with STD Code
14. Fax Number with STD Code
15. Mobile Number
16. E-mail Address
Note: In case of partnership firm and limited company certified copy of partnership deed/
Articles of Association and Memorandum of Association along with registration
certificate of the company shall have to be enclosed.
Signature of Bidder with Seal
Date: _____________
Section 2 –Annexure - H
Page 27 of 78
Annexure – I
(See clause 14 of Section 2 -ITB)
Note:
1. Technical Proposal should be uploaded duly page numbered and indexed.
2. Technical Proposal uploaded otherwise will not be considered.
Section 2 –Annexure - I
Page 28 of 78
Annexure - I (Format: I-1)
(See clause 14 of Section 2 -ITB)
FINANCIAL & PHYSICAL EXPERIENCE DETAILS
A. Financial Requirement:
The bidder should have completed either of the below:
a) three similar works each costing not less than the amount equal to 20% of the
probable amount of contract during the last 3 financial years; or
b) two similar works each costing not less than the amount equal to 30% of the
probable amount of contract during the last 3 financial years; or
c) one similar work of aggregate cost not less than the amount equal to 50% of the
probable amount of contract in any one financial year during the last 3 financial
years;
To be filled in by the contractor:
i. Details of successfully completed similar works shall be furnished in the following format.
ii. Certificate duly signed by the employer shall also be enclosed for each completed similar
work.
B. Physical Requirement:
Execution of similar items of work in any one financial year during the last 3 financial
years should not be less than the minimum physical requirement fixed for the work.
SNo Particulars Actual Quantity Executed
(To be filled in by the contractor)
Year – 1 Year – 2 Year – 3
1 Physical qualification required Yes/ No
2 Earthwork
3 Concrete work
Note: 1. Certificate duly signed by the employer shall be enclosed for the actual quantity
executed in any one year during the last 3 financial years.
2. Similar works: The similarity shall be based on the physical size, complexity, methods
technology or other characteristics of main items of work viz. earth work, cement concrete,
Reinforced cement concrete, brick masonry, stone masonry etc.
Page 29 of 78
Annexure - I (Format: I -2)
(See clause 14 of Section 2 -ITB)
ANNUAL TURN OVER
Requirement:
Average annual construction turnover on the construction works not less than 50% of
the probable amount of contract during the last 5 financial years;
Note:
i. Annual turnover of construction should be certified by the Chartered Accountant.
ii. Audited balance sheet including all related notes, and income statements for the above
financial years to be enclosed.
Bid Capacity
A = Maximum value of civil engineering works executed in any one year during the
last five year (10% weightage per year shall be given to bring the value
of work executed at present price level)
B= Proposed contract period in years.
C= Amount of work in hand at present.
Page 30 of 78
Annexure - I (Format: I -3)
(See clause 14 of Section 2 –ITB & Clause 6 of GCC)
Name of Personnel
Similar workexperience
Similar workexperience
Minimumrequirement
Total WorkExperience
Total WorkExperience
Qualification
Qualification
Key Position
Key Position
S. No.
S. No.
Age
Age
Page 31 of 78
Annexure I (Format: I -4)
(See clause 14 of Section 2 -ITB)
List of Key Equipments/ Machines for Quality Control Labs
Machinery Machinery
Page 32 of 78
Annexure - I (Format: I -5)
(See clause 14 of Section 2 -ITB)
List of Key Equipments/ Machines for Construction Work
Name of Name of
S. No. Equipment/ Quantity Equipment/ Quantity
Machinery Machinery
Page 33 of 78
Annexure – J
(See clause 14 of Section 2 -ITB)
FINANCIAL BID
(To Be Contained in Envelope-C)
NAME OF WORK __________________________________________________________
________________________________________________________________________
I/We hereby bid for the execution of the above work within the time specified at the
rate (in figures) _______ (in words)___________ _________________________________
percent below/ above or at par based on the Bill of Quantities and item wise rates given
therein in all respects and in accordance with the specifications, designs, drawings and
instructions in writing in all respects in accordance with such conditions so far as
applicable. I/We have visited the site of work and am/ are fully aware of all the difficulties
and conditions likely to affect carrying out the work. I/We have fully acquainted
myself/ourselves about the conditions in regard to accessibility of site and quarries/kilns,
nature and the extent of ground, working conditions including stacking of materials,
installation of tools and plant conditions effecting accommodation and movement of
labour etc. required for the satisfactory execution of contract.
Should this bid be accepted, I/We hereby agree to abide by and fulfill all the terms
and provisions of the said conditions of contract annexed hereto so far as applicable, or in
default thereof to forfeit and pay to the Governor of Madhya Pradesh or his successors in
office the sums of money mentioned in the said conditions.
Note:
i. Only one rate of percentage above or below or at par based on the Bill of Quantities
and item wise rates given therein shall be quoted.
ii. Percentage shall be quoted in figures as well as in words. If any difference in figures
and words is found lower of the two shall be taken as valid and correct rate. If the
bidder is not ready to accept such valid and correct rate and declines to furnish
performance security and sign the agreement his earnest money deposit shall be
forfeited.
iii. In case the percentage "above" or "below" is not given by a bidder, his bid shall be
treated as non-responsive.
iv. All duties, taxes, and other levies payable by the bidder shall be included in the
percentage quoted by the bidder.
Signature of Bidder
Name of Bidder
The above bid is hereby accepted by me on behalf of the Governor of Madhya
Pradesh dated the _________ day of __________ 20__
____________
Signature of Officer by whom accepted
Section 2 –Annexure - J
Page 34 of 78
Annexure – L
(See clause 21 of Section 2 -ITB)
Yours Faithfully
Executive Engineer
Section 2 –Annexure - L
Page 36 of 78
Annexure – M
(See clause 22 of Section 2 -ITB)
PERFORMANCE SECURITY
To
_____________________[name of Employer]
_____________________
_____________________[address of Employer]
_____________________
* An amount shall be inserted by the Guarantor, representing the percentage the Contract
Price specified in the Contract including additional security for unbalanced Bids, if any and
denominated in Indian Rupees.
Section 2 –Annexure - M
Page 37 of 78
SECTION 3
Conditions of Contract
Part – I General Conditions of Contract [GCC]
Table of Clauses of GCC
Clause Clause
No
Particulars No
Particulars
A. General 21 Payments for Variations and / or Extra
Quantities
1 Definitions 22 No compensation for alterations in or restriction
of work to be carried out.
2 Interpretations and Documents 23 No Interest Payable
3 Language and Law 24 Recovery from Contractors
4 Communications 25 Tax
5 Subcontracting 26 Check Measurements
6 Personnel 27 Termination by Engineer in Charge
7 Force Majeure 28 Payment upon Termination
8 Contractor's Risks 29 Performance Security
9 Liability For Accidents To Person 30 Security Deposit
10 Contractor to Construct the Works 31 Price Adjustment
11 Discoveries 32 Mobilization and Construction Machinery
Advance
12 Dispute Resolution System 33 Secured Advance
B. Time Control 34 Payments Certificates
13 Programme E. Finishing the Contract
14 Extension of Time 35 Completion Certificate
15 Compensation for Delay 36 Final Account
16 Contractor’s quoted percentage F. Other Conditions of Contract
C. Quality Control 37 Currencies
17 Tests 38 Labour
18 Correction of Defects noticed 39 Compliance with Labour Regulations
during the Defect Liability Period
D. Cost Control 40 Audit and Technical Examination
19 Variations - Change in original 41 Death or Permanent Invalidity of Contractor
Specifications, Designs, Drawings
etc.
20 Extra Items 42 Jurisdiction
Page 38 of 78
A. General
1. DEFINITIONS
1.1. Bill of Quantities: means the priced and completed Bill of Quantities forming part
of the Bid.
1.2. Chief Engineer: means Chief Engineer of the zone/ basin concerned.
1.3. Completion: means completion of the work as certified by the Engineer-in-Charge,
in accordance with provisions of agreement.
1.4. Contract: means the Contract between the Employer and the Contractor to
execute, complete and/or maintain the work. Agreement is synonym of Contract
and carries the same meaning wherever used.
1.5. Contract Data: means the documents and other information which comprise of the
Contract.
1.6. Contractor: means a person or legal entity whose bid to carry out the work has
been accepted by the Employer.
1.7. Contractor's bid: means the completed bid document submitted by the Contractor
to the Employer.
1.8. Contract amount: means the amount of contract worked out on the basis of
accepted bid.
1.9. Completion of work: means completion of the entire contracted work. Exhaustion
of quantity of any particular item mentioned in the bid document shall not imply
completion of work or any component thereof.
1.10. Day: means the calendar day.
1.11. Defect: means any part of the work not completed in accordance with the
specifications included in the contract.
1.12. Department: means Department of the State Government viz. Water Resources
Department, Public Works Department, Public Health Engineering Department,
Rural Engineering Service and any other organisation which adopts this document.
1.13. Drawings: means drawings including calculations and other information provided
or approved by the Engineer-in-Charge.
1.14. Employer: means the party as defined in the Contract Data, who employs the
Contractor to carry out the work. The Employer may delegate any or all functions
to a person or body nominated by him for specified functions. The word Employer /
Government / Department wherever used denote the Employer.
1.15. Engineer: means the person named in the Contract Data.
1.16. Engineer in charge: means the person named in the Contract Data.
1.17. Equipment: means the Contractor's machinery and vehicles brought temporarily to
the Site for execution of work.
1.18. Government: means Government of Madhya Pradesh.
1.19. In Writing: means communicated in written form and delivered against receipt.
1.20. Material: means all supplies, including consumables, used by the Contractor for
incorporation in the work.
Page 39 of 78
1.21. Superintending Engineer: means Superintending Engineer-in-Charge of the Circle
concerned.
1.22. Stipulated period of completion: means the period in which the Contractor is
required to complete the work. The stipulated period is specified in the Contract
Data.
1.23. Specification: means the specification of the work included in the Contract and any
modification or addition made or approved by the Engineer-in-Charge.
1.24. Start Date: means the date of signing of agreement for the work.
1.25. Sub-Contractor: means a person or corporate body who has a Contract with the
Contractor, duly authorised to carry out a part of the construction work under the
Contract.
1.26. Temporary Work: means work designed, constructed, installed, and removed by
the Contractor that are needed for construction or installation of the work.
1.27. Tender/Bid, Tenderer/Bidder: are the synonyms and carry the same meaning
where ever used.
1.28. Variation: means any change in the work which is instructed or approved as
variation under this contract.
1.29. Work: The expression "work" or "works" where used in these conditions shall
unless there be something either in the subject or context repugnant to such
construction, be construed and taken to mean the work by virtue of contract,
contracted to be executed, whether temporary or permanent and whether original,
altered, substituted or additional.
2. INTERPRETATIONS AND DOCUMENTS
2.1 Interpretations
In the contract, except where the context requires otherwise:
a. words indicating one gender include all genders;
b. Words indicating the singular also include the plural and vice versa.
c. provisions including the word “agree”, “agreed” or “agreement” require the
agreement to be recorded in writing;
d. written” or “in writing” means hand-written, type-written, printed or
electronically made, and resulting in a permanent record;
Page 40 of 78
3. Language and Law
The language of the Contract and the law governing the Contract are stated in the
Contract Data.
4. Communications
All certificates, notice or instruction to be given to the Contractor by
Employer/Engineer shall be sent to the address or contact details given by the
Contractor in [Annexure H of ITB]. The address and contact details for
communication with the Employer/Engineer shall be as per the details given in the
Contract Data. Communication between parties that are referred to in the
conditions shall be in writing. The notice sent by facsimile (fax) or other electronic
means (email) shall also be effective on confirmation of the transmission. The
notice sent by registered post or speed post shall be effective on delivery or at the
expiry of the normal delivery period as undertaken by the postal service. In case of
any change in address for communication, the same shall be immediately notified
to Engineer-in-Charge.
5. Subcontracting
Subcontracting shall be permitted for contracts of value more than amount
specified in the Contract Data with following conditions.
a. The Contractor may subcontract up to 25 percent of the contract price with the
approval of the Employer in writing, but will not assign the Contract.
Subcontracting shall not alter the Contractor's obligations.
b. Following shall not form part of subcontracting:
i. Hiring of labour through a labour contractor.
ii. The purchase of Materials to be incorporated in the works.
iii. Hiring of plant & machinery
c. The sub-contractor will have to be registered in the appropriate category in the
centralised registration system for contractors of the GoMP.
6. Personnel
6.1 The Contractor shall employ for the construction work and routine maintenance
the technical personnel as provided in the Annexure I-3 of Bid Data Sheet, if
applicable. If the Contractor fails to deploy required number of technical staff,
recovery as specified in the Contract Data will be made from the Contractor.
6.2 If the Engineer asks the Contractor to remove a person who is a member of the
Contractor's staff or work force, stating the reasons, the Contractor shall ensure
that the person leaves the Site within three days and has no further connection
with the Works in the Contract.
Page 41 of 78
7. Force Majeure
8. Contractor's Risks
8.1 All risks of loss or damage to physical property and of personal injury and death
which arise during and in consequence of the performance of the Contract are the
responsibility of the Contractor.
Page 42 of 78
8.2 All risks and consequences arising from the inaccuracies or falseness of the
documents, drawing, designs, other documents and/or information submitted by
the contractor shall be the responsibility of the Contractor alone, notwithstanding
the fact that the designs/ drawings or other documents have been approved by
the department.
11. Discoveries
Anything of historical or other interest or of significant value unexpectedly
discovered on the Site shall be the property of the Employer. The Contractor shall
notify the Engineer of such discoveries and carry out the Engineer's instructions for
dealing with them.
Page 43 of 78
12.2 No dispute can be raised after 45 days of its first occurrence. Any dispute raised
after expiry of 45 days of its first occurrence shall not be entertained and the
Employer shall not be liable for claims arising out of such dispute.
12.3 The Competent Authority shall decide the matter within 45 days.
12.4 Appeal against the order of the Competent Authority can be preferred within 30
days to the Appellate Authority as defined in the Contract Data. The Appellate
Authority shall decide the dispute within 45 days.
12.5 Appeal against the order of the Appellate Authority can be preferred before the
Madhya Pradesh Arbitration Tribunal constituted under Madhya Pradesh
Madhyastham Adhikaran Adhiniyam, 1983.
12.6 The Contractor shall have to continue execution of the Works with due
diligence notwithstanding pendency of a dispute before any authority or forum.
B. Time Control
13. Programme
13.1 Within the time stated in the Contract Data, the Contractor shall submit to the
Engineer for approval a Programme showing the general methods,
arrangements, order and timing for all the activities for the construction of
works.
13.2 The program shall be supported with all the details regarding key personnel,
equipment and machinery proposed to be deployed on the works for its
execution. The contractor shall submit the list of equipment and machinery
being brought to site, the list of key personnel being deployed, the list of
machinery/equipment being placed in field laboratory and the location of field
laboratory along with the Programme.
13.3 An update of the Programme shall be a programme showing the actual progress
achieved on each activity and the effect of the progress achieved on the timing
of the remaining Works, including any changes to the sequence of the activities.
13.4 The Contractor shall submit to the Engineer for approval an updated
Programme at intervals no longer than the period stated in the Contract Data. If
the Contractor does not submit an updated Programme within this period, the
Engineer may withhold the amount stated in the Contract Data from the next
payment certificate and continue to withhold this amount until the next
payment after the date on which the overdue Programme has been submitted.
13.5 The Engineer's approval of the Programme shall not alter the Contractor's
obligations.
Page 44 of 78
14. Extension of Time
14.1. If the Contractor desires an extension of time for completion of the work on the
ground of his having been unavoidably hindered in its execution or on any other
grounds, he shall apply, in writing, to the Engineer-in-charge, on account of
which he desires such extension. Engineer-in-Charge shall forward the
aforesaid application to the Competent Authority as prescribed.
14.2 The competent authority shall grant such extension at each such occasion
within a period of 30 days of receipt of application from contractor and shall not
wait for finality of work. Such extensions shall be granted in accordance with
provisions under clause- 15 of this agreement.
14.3 In case the work is already in progress, the Contractor shall proceed with the
execution of the works, including maintenance thereof, pending receipt of the
decision of the competent authority as aforesaid with all due diligence.
Page 45 of 78
C. Quality Control
17. Tests
17.1 The Contractor shall be responsible for:
a. Carrying out the tests prescribed in specifications, and
b. For the correctness of the test results, whether preformed in his laboratory
or elsewhere.
17.2 The contractor shall have to establish field laboratory within the time specified
and having such equipments as are specified in the Contract Data.
17.3 Failure of the Contractor to establish laboratory shall attract such penalty as is
specified in the Contract Data.
19.1 The Engineer-in-charge shall have power to make any alterations, omissions or
additions to or substitutions in the original specifications, drawings, designs and
instructions, that may appear to him to be necessary during the progress of the
work and the contractor shall carry out the work in accordance with any
instructions which may be given to him in writing signed by the Engineer-in-
charge, and such alterations, omission, additions or substitutions shall not
invalidate the contract and any altered, additional or substituted work, which
the contractor may be directed to do in the manner above specified, as part of
the work, shall be carried out by the contractor on the same conditions in all
respects on which he agrees to do the main work.
Page 46 of 78
19.2 The time for the completion of the work shall be adjusted in the proportion that
the altered, additional or substituted work bears to the original contract work
and the certificate of the Engineer-in-charge shall be conclusive as to such
proportion.
a. The contractor is bound to carry out the additional (Extra quantity), work at
the same rates as are specified in the contract for the work.
b. If the item is not in the priced BOQ and is included in the SOR of the
department, the rate shall be arrived at by applying the quoted tender
percentage on the SOR rate.
c. If the rates for the altered or substituted work are not provided in
applicable SOR - such rates will be derived from the rates for a similar class
(type) of work as is provided in the contract (priced BOQ) for the work.
d. If the rates for the altered, substituted work cannot be determined in the
manner specified in the sub clause (c) above - then the rates for such
composite work item shall be worked out on the basis of the concerned
Schedule of Rates minus/plus the percentage quoted by the contractor.
e. If the rates for a particular part or parts of the item is not in the Schedule of
Rates and the rates for the altered, or substituted work item cannot be
determined in the manner specified in sub clause (b) to (d) above, the rate
for such part or parts will be determined by the Competent Authority as
defined in the Contract Data on the basis of the rate analysis derived out of
prevailing market rates when the work was done.
Page 47 of 78
f. But under no circumstances, the contractor shall suspend the work on the
plea of non-acceptability of rates on items falling under sub clause (a) to (d).
In case the contractor does not accept the rate approved by the Engineer in
Charge for a particular item, the contractor shall continue to carry out the
item at the rates determined by the Competent Authority. The decision on
the final rates payable shall be arrived at through the dispute settlement
procedure.
Page 48 of 78
25.2 The liability, if any, on account of quarry fees, royalties, octroi and any other
taxes and duties in respect of materials actually consumed on public work,
shall be borne by the Contractor.
25.3 Any changes in the taxes due to change in legislation or for any other reason
shall not be payable to the contractor.
26.1 The department reserves to itself the right to prescribe a scale of check
measurement of work in general or specific scale for specific works or by other
special orders.
26.2 Checking of measurement by superior officer shall supersede measurements by
subordinate officer(s), and the former will become the basis of the payment.
26.3 Any over/excess payments detected, as a result of such check measurement or
otherwise at any stage up to the date of completion of the defect liability period
specified in this contract, shall be recoverable from the Contractor, as per
clause 24 above.
Page 49 of 78
27.3 In any of these events or circumstances, the Engineer in Charge may, upon
giving 14 days’ notice to the Contractor, terminate the Contract and expel the
Contractor from the Site. However, in the case of sub-paragraph (b) or (g) of
clause 27.2, the Engineer in Charge may terminate the Contract immediately.
27.4 Notwithstanding the above, the Engineer-in-Charge may terminate the Contract
for convenience by giving notice to the Contractor.
Page 50 of 78
31. Price Adjustment
31.1 Applicability
1. Price adjustment shall be applicable only if provided for in the Contract Data.
2. The price adjustment clause shall apply only for the works executed from
the date of signing of the agreement until the end of the initial intended
completion date or extensions granted for reasons attributed to the
Employer by the Engineer.
3. The Contractor shall not be entitled to any benefit arising from the price
adjustment clause for extension in the contract period for reasons
attributed to the Contractor.
4. In the Force Majeure event the price escalation clause shall apply.
31.2 Procedure
1. Contract price shall be adjusted for increase or decrease in rates and price
of labour, materials, fuels and lubricants in accordance with following
principles and procedures and as per formula given in the contract data.
2. The price adjustable shall be determined during each quarter from the
formula given in the contract data.
3. Following expression and meaning are assigned to the work done during
each quarter:
R = Total value of work during the quarter. It would include the amount of secured
advance granted, if any, during the quarter, less the amount of secured advance
recovered, if any during the quarter, less value of material issued by the
department, if any, during the quarter.
31.3 To the extent that full compensation for any rise or fall in costs to the
contractor is not covered by the provisions of this or other clauses in the
contract, the unit rates and prices included in the contract shall be deemed to
include amounts to cover the contingency of such other rise or fall in costs.
31.4 The index relevant to any quarter, for which such compensation is paid, shall be
the arithmetical average of the indices relevant of the calendar month.
31.5 For the purpose of clarity it is pointed out that the price adjustment may be either
positive or negative, i.e. if the price adjustment is in favour of the Employer, the
same shall be recovered from the sums payable to the Contractor.
Page 51 of 78
32. Mobilization and Construction Machinery Advance
Page 52 of 78
(c) The value of work executed shall be determined, based on the measurements
approved by the Engineer/ Engineer-in-charge.
(d) The value of work executed shall comprise the value of the quantities of the
items in the Bill of Quantities completed.
(e) The value of work executed shall also include the valuation of Variations
and Compensation Events.
(f) All payments shall be adjusted for deductions for advance payment, security
deposit, other recoveries in terms of contract and taxes at source as applicable
under the law.
(g) The Engineer may exclude any item certified in a previous certificate or reduce
the proportion of any item previously certified in any certificate in the light of
later information.
(i) Intermediate payment shall not preclude the requiring of bad, unsound and
imperfect or unskilled work to be removed and taken away and reconstructed
or be considered as an admission of the due performance of the contractor any
part thereof, in any respect or the occurring of any claim.
(j) The payment of final bill shall be governed by the provisions of clause 36 of GCC.
Page 53 of 78
36. Final Account
36.1 The Contractor shall supply the Engineer with a detailed account of the total
amount that the Contractor considers payable for works under the Contract
within 21 days of issue of certificate of physical completion of works. The
Engineer shall issue a Defects Liability Certificate and certify any payment that is
due to the Contractor within 45 days of receiving the Contractor’s account if it is
correct and complete. If the account is not correct or complete, the Engineer
shall issue within 45 days a schedule that states the scope of the corrections or
additions that are necessary. If the Account is still unsatisfactory after it has
been resubmitted, the matter shall be referred to the Competent Authority as
defined in the Contract Data, who shall decide on the amount payable to the
Contractor after hearing the Contractor and the Engineer in Charge.
36.2 In case the account is not received within 21 days of issue of Certificate of
Completion as provided in clause 35.1 above, the Engineer shall proceed to
finalise the account and issue a payment certificate within 28 days.
38.1 The Contractor shall, unless otherwise provided in the Contract, make his own
arrangements for the engagement of all staff and labour, local or other, and for
their payment, housing, feeding and transport.
38.2 The Contractor shall, if required by the Engineer, deliver to the Engineer a
return in detail, in such form and at such intervals as the Engineer may
prescribe, showing the staff and the numbers of the several classes of labour
from time to time employed by the Contractor on the Site and such other
information as the Engineer may require.
Page 54 of 78
39. Compliance with Labour Regulations
39.1. During continuance of the Contract, the Contractor and his sub-Contractors shall
abide at all times by all existing labour enactments and rules made there under,
regulations, notifications and bye laws of the State or Central Government or local
authority and any other labour law (including rules), regulations, bye laws that may
be passed or notification that may be issued under any labour law in future either
by the State or the Central Government or the local authority. Salient features of
some of the major labour laws that are applicable to construction industry are
given in the Contract Data. The Contractor shall keep the Employer indemnified in
case any action is taken against the Employer by the competent authority on
account of contravention of any of the provisions of any Act or rules made their
under, regulations or notifications including amendments. If the Employer is caused
to pay or reimburse, such amounts as may be necessary to cause or observe, or for
non-observance of the provisions stipulated in the
notifications/byelaws/Acts/Rules/ regulations including amendments, if any, on the
part of the Contractor, the Engineer/Employer shall have the right to deduct from
any money due to the Contractor including his amount of performance security.
The Employer/Engineer shall also have right to recover from the Contractor any
sum required or estimated to be required for making good the loss or damage
suffered by the Employer. The employees of the Contractor and the Sub-Contractor
in no case shall be treated as the employees of the Employer at any point of time.
Page 55 of 78
41. Death or Permanent Invalidity of Contractor
If the Contractor is an individual or a proprietary concern, partnership concern, dies
during the currency of the contract or becomes permanently incapacitated, where
the surviving partners are only minors, the contract shall be closed without levying
any damages/ compensation as provided for in clause 28.2 of the contract
agreement. However, if the competent authority is satisfied about the competence
of the survivors, then the competent authority shall enter into a fresh agreement for
the remaining work strictly on the same terms and conditions under which the
contract was awarded.
42. Jurisdiction
This contract has been entered into the State of Madhya Pradesh and its validity,
construction, interpretation and legal effect shall be subjected to the courts at the
place where this agreement is entered into. No other jurisdiction shall be applicable.
[End of GCC]
Page 56 of 78
ANNEXURE – N
(See clause 10 of Section 3 – GCC )
Drawings
List of drawings –
Section 3 – Annexure N
Page 60 of 78
ANNEXURE – P
(See clause 15 of Section 3 -GCC )
If the contractor fails to achieve the milestones, and the delay in execution of work
is attributable to the contractor, the Employer shall retain an amount from the
sums payable and due to the contractor as per following scale -
ii. Slippage exceeding 25% but Up to 50% in financial target during the
milestone under consideration
- 5% of the work remained unexecuted in the related time span..
iii. Slippage exceeding 50% but Up to 75% in financial target during the
milestone under consideration
-7.5% of the work remained unexecuted in the related time span..
Note: For arriving at the dates of completion of time span related to different milestones,
delays which are not attributable to the Contractor shall be considered. The slippage
on any milestone is if made good in subsequent milestones or at the time of stipulated
period of completion, the amount retained as above shall be refunded. In case the
work is not completed within the stipulated period of completion along with all such
extensions which are granted to the Contractor for either Employer’s default or Force
Majeure, the compensation shall be levied on the contractor at the rate of 0.05% per
day of delay limited to a maximum of 10% of contract price.
The decision of Superintending Engineer shall be final and binding upon both
the parties.
Section 3 – Annexure P
Page 62 of 78
ANNEXURE - R
(See clause 31 of Section 3 -GCC )
Price Adjustment
Percentage of
S.No Component
component in the work
1 Cement - Pc
2 Steel - Ps
3 Bitumen - Pb
4 POL - Pf
Note : For the application of this clause, index of Grey Cement has been chosen to
represent Cement group.
Section 3 – Annexure R
Page 64 of 78
Vs= 0.85 x PS x /100 x R x (S1-S0)/S0
Vs= Increase or decrease in the cost of work during the month under consideration
due to changes in the rates for steel.
S0= The all India wholesale price index for steel (Bars and Rods) on the date of
opening of Bids as published by the Ministry of Industrial Development,
Government of India, New Delhi. (www.eaindustry.nic.in)
Si = The all India average wholesale price index for steel (Bars and Rods) for the
month under consideration as published by Ministry of Industrial
Development, New Delhi. (www.eaindustry.nic.in)
Ps= Percentage of steel component of the work.
Note : For the application of this clause, index of Bars and Rods has been chosen to
represent steel group.
Adjustment of bitumen component
(iv) Price adjustment for increase or decrease is the cost of bitumen shall be paid
in accordance with the following formula:
Vb= 0.85x Pb / 100xRx( Bi – Bo) / Bo
Vb= Increase or decrease in the cost of work during the month under
consideration due to changes in rates for bitumen.
Bo = The official retail price of bitumen at the IOC depot at nearest
center on the date of opening of Bids.
Bi = The official retail price of bitumen of IOC depot at nearest center for
th
the 15 day of the month under consideration.
Pb = Percentage of bitumen component of the work.
( V) Price adjustment for increase or decrease in cost of POL ( fuel and lubricant )
shall be paid in accordance with the following formula:
Note : For the application of this clause, the price of High Speed Diesel has been
chosen to represent fuel and lubricants group.
Section 3 – Annexure R
Page 65 of 78
Annexure – S
(See clause 32 of Section 3 -GCC )
Section 3 – Annexure S
Page 66 of 78
Annexure – T
(See clause 33 of Section 3 -GCC )
____________ (hereinafter called the contractor which expression shall where the context
so admits or implies be deemed to include his executors, administrators and assigns) or
the one part and the Employer of the other part.
AND WHEREAS the contractor has applied to the Employer that he may be
allowed advanced on the security of materials absolutely belonging to him and brought by
him to the site of the works the subject of the said agreement for use in the construction
of such of the works as he has undertaken to executive at rates fixed for the finished work
(inclusive of the cost of materials and labour and other charges)
AND WHEREAS the Employer has agreed to advance to the Contractor the sum
of Rupees _________________________ on the security of materials the quantities and other
particulars of which are detailed in Accounts of Secured Advance attached to the Running
Account Bill for the said works signed by the Contractor on _________ and the Employer has
reserved to himself the option of making any further advance or advances on the security of
other materials brought by the Contractor to the site of the said works.
Section 3 – Annexure T
Page 67 of 78
(1) the Contractor as aforesaid and all or any further sum of sums advanced as
aforesaid shall be employed by the Contractor in or towards expending the
execution of the said works and for no other purpose whatsoever.
(2) That the materials details in the said Account of Secured Advances which have been
offered to and accepted by the Employer as security are absolutely the Contractor's
own propriety and free from encumbrances of any kind and the contractor will not
make any application for or receive a further advance on the security of materials
which are not absolutely his own property and free from encumbrances of any kind
and the Contractor indemnified the Employer against all claims to any materials in
respect of which an advance has be made to him as aforesaid.
(3) That the materials detailed in the said account of Secured Advances and all other
materials on the security of which any further advance or advances may hereafter
be made as aforesaid (hereafter called the said materials) shall be used by the
Contractor solely in the execution of the said works in accordance with the
directions of the Engineer.
(4) That the Contractor shall make at his own cost all necessary and adequate
arrangements for the proper watch, safe custody and protection against all risks of
the said materials and that until used in construction as aforesaid the said materials
shall remain at the site of the said works in the Contractor's custody and on his
own responsibility and shall at all times be open to inspection by the Engineer or
any officer authorized by him. In the event of the said materials or any part thereof
being stolen, destroyed or damaged or becoming deteriorated in a greater degree
than is due to reasonable use and wear thereof the Contractor will forthwith
replace the same with other materials of like quality or repair and make good the
same required by the Engineer.
(5) That the said materials shall not be removed from the site of the said works except
with the written permission of the Engineer or an officer authorized by him on that
behalf.
Section 3 – Annexure T
Page 68 of 78
(6) That the advances shall be repayable in full when or before the Contract receives
payment from the Employer of the price payable to him for the said works under
the terms and provisions of the said agreement. Provided that if any intermediate
payments are made to the Contractor on account of work done than on the
occasion of each such payment the Employer will be at liberty to make a recovery
from the Contractor's bill for such payment by deducting there from the value of
the said materials than actually used in the construction and in respect of which
recovery has not been made previously, the value for this purpose being
determined in respect of each description of materials at the rates at which the
amounts of the advances made under these presents were calculated.
(7) That if the Contractor shall at any time make any default in the performance or
observance in any respect of any of the terms and provisions of the said agreement
or of these presents the total amount of the advance or advances that may still be
owing of the Employer shall immediately on the happening of such default be re-
payable by the Contractor to be the Employer together with interest thereon at
twelve percent per annum from the date or respective dates of such advance or
advances to the date of repayment and with all costs, charges, damages and
expenses incurred by the Employer in or for the recovery thereof or the
enforcement of this security or otherwise by reason of the default of the
Contractor and the Contractor hereby covenants and agrees with the Employer to
reply and pay the same respectively to him accordingly.
(8) That the Contractor hereby charges all the said materials with the repayment to
the Employer of the said sum of Rupees____________________________ and any
further sum of sums advanced as aforesaid and all costs, charges, damages and
expenses payable under these presents PROVIDED ALWAYS and it is hereby agreed
and declared that notwithstanding anything in the said agreement and without
prejudice to the power contained therein if and whenever the covenant for
payment and repayment here-in-before contained shall become enforceable and
the money owing shall not be paid in accordance there with the Employer may at
any time thereafter adopt all or any of the following courses as he may deem best:
Section 3 – Annexure T
Page 69 of 78
(a) Seize and utilise the said materials or any part thereof in the completion of the
said works on behalf of the contractor in accordance with the provision in that
behalf contained in the said agreement debiting the contractor with the actual
cost of effecting such completion and the amount due to the contractor with
the value of work done as if he had carried it out in accordance with the said
agreement and at the rates thereby provided. If the balance is against the
contractor, he is to pay same to the Employer on demand.
(b) Remove and sell by public auction the seized materials or any part thereof and
out of the moneys arising from the sale retain all the sums aforesaid repayable
or payable to the Employer under these presents and pay over the surplus (if
any) to the Contractor.
(C) Deduct all or any part of the moneys owing out of the security deposit or any
sum due to the Contractor under the said agreement.
(9) That except in the event of such default on the part of the contractor as aforesaid
interest on the said advance shall not be payable.
(10) That in the event of any conflict between the provisions of these presents and the
said agreement the provisions of these presents shall prevail and in the event of
any dispute or difference arising over the construction or effect of these presents
the settlement of which has not been here-in-before expressly provided for the
same shall be referred to the Employer whose decision shall be final and the
provision of the Indian Arbitration Act for the time being in force shall apply to any
such reference.
Section 3 – Annexure T
Page 70 of 78
Annexure – U
(See clause 35 of Section 3 -GCC )
Name of Work:
……………………………………………….…………………………………………………………………………………
………………………….……………………………………………….……………………………………………….………
………………………………………………………………………….………………………………………………………..
Certified that the above mentioned work was physically completed on ……………….
(date) and taken over on ……………….. (date) and that I have satisfied myself to best of
my ability that the work has been done properly.
Date of issue
Executive Engineer
….....................................
……………………………..
Section 3 – Annexure U
Page 71 of 78
Annexure – V
(See clause 35 of Section 3 -GCC )
Name of Work:
……………………………………………….…………………………………………………………………………………
………………………….……………………………………………….……………………………………………….………
………………………………………………………………………….………………………………………………………..
Certified that the above mentioned work was physically completed on ……………….
(date) and taken over on ……………….. (date).
Agreemented amount Rs. …………………..
Final Amount paid to contractor Rs. ----------------------
I have satisfied myself to best of my ability that the work has been done properly.
Date of issue
Executive Engineer
….....................................
……………………………..
Section 3 – Annexure V
Page 72 of 78
Annexure – W
(See clause 39 of Section 3 -GCC )
a) Workmen Compensation Act 1923: - The Act provides for compensation in case of
injury by accident arising out of and during the course of employment.
b) Payment of Gratuity Act 1972: - Gratuity is payable to an employee under the Act
on satisfaction of certain conditions on separation if an employee has completed
the prescribed minimum years (say, five years) of service or more or on death the
rate of prescribed minimum days’(say, 15 days) wages for every completed year of
service. The Act is applicable to all establishments employing the prescribed
minimum number (say, 10) or more employees.
c) Employees P.F. and Miscellaneous Provision Act 1952: The Act Provides for
monthly contributions by the Employer plus workers at the rate prescribed (say,
10% or 8.33%). The benefits payable under the Act are:
i. Pension or family pension on retirement or death as the case may be.
ii. Deposit linked insurance on the death in harness of the worker.
iii. Payment of P.F. accumulation on retirement/death etc.
d) Maternity Benefit Act 1951: - The Act provides for leave and some other benefits
to women employees in case of confinement or miscarriage etc.
e) Contract Labour (Regulation & Abolition) Act 1970: - The Act provides for certain
welfare measures to be provided by the Contractor to contract labour and in case
the Contractor fails to provide, the same are required to be provided, by the
Principal Employer by Law. The principal Employer is required to take Certificate of
Registration and the Contractor is required to take license from the designated
Officer. The Act is applicable to the establishments or Contractor of Principal
Employer if they employ prescribed minimum (say 20) or more contract labour.
f) Minimum Wages Act 1948: - The Employer is to pay not less than the Minimum
Wages fixed by appropriate Government as per provisions of the Act if the
employment is a scheduled employment. Construction of buildings, roads, runways
is scheduled employment.
g) Payment of Wages Act 1936: - It lays down as to by what date the wages are to be
paid, when it will be paid and what deductions can be made from the wages of the
workers.
h) Equal Remuneration Act 1979: - The Act provides for payment of equal wages for work
of equal nature to male and female workers and for not making discrimination against
female employees in the matters of transfers, training and promotions etc.
Section 3 – Annexure W
Page 73 of 78
i) Payment of Bonus Act 1965: - The Act is applicable to all establishments employing
prescribed minimum (say, 20) or more workmen. The Act provides for payments of
annual bonus within the prescribed range of percentage of wages to employees
drawing up to the prescribed amount of wages, calculated in the prescribed
manner. The Act does not apply to certain establishments. The newly set-up
establishments are exempted for five years in certain circumstances. States may
have different number of employment size.
j) Industrial Disputes Act 1947: - The Act lays down the machinery and procedure for
resolution of industrial disputes, in what situations a strike or lock-out becomes
illegal and what are the requirements for laying off or retrenching the employees
or closing down the establishment.
l) Trade Unions Act 1926: - The Act lays down the procedure for registration of trade
unions of workmen and Employers. The Trade Unions registered under the Act
have been given certain immunities from civil and criminal liabilities.
m) Child Labour (Prohibition & Regulation) Act 1986: - The Act prohibits employment of
children below 14 years of age in certain occupations and processes and provides for
regulations of employment of children in all other occupations and processes.
Employment of child labour is prohibited in building and construction industry.
Section 3 – Annexure W
Page 74 of 78
o) The Building and Other Construction workers (Regulation of Employment and
Conditions of Service) Act 1996 and the Cess Act of 1996: - All the establishments
who carry on any building or other construction work and employs the prescribed
minimum (say, 10) or more workers are covered under this Act. All such
establishments are required to pay cess at the rate not exceeding 2% of the cost of
construction as may be modified by the Government. The Employer of the
establishment is required to provide safety measures at the building or
construction work and other welfare measures, such as canteens, first-aid facilities,
ambulance, housing accommodations for workers near the work place etc. The
Employer to whom the Act applies has to obtain a registration certificate from the
Registering Officer appointed by the Government.
p) Factories Act 1948: - The Act lays down the procedure for approval of plans before
setting up a factory, health and safety provisions, welfare provisions, working
hours, annual earned leave and rendering information regarding accidents or
dangerous occurrences to designated authorities. It is applicable to premises
employing the prescribed minimum (say, 10) persons or more with aid of power or
another prescribed minimum (say, 20) or more persons without the aid of power
engaged in manufacturing process.
Section 3 – Annexure W
Page 75 of 78
SECTION 3
Conditions of Contract
Part – II Special Conditions of Contract [SCC]
Page 76 of 78
SECTION 4
BILL OF QUANTITIES (BOQ)
General Description of work:………………………………………………………………………………………………
…………………………………………………………………………………………………………………………………………
…………………………………………………………………………………………………………………………………………
Probable Amount of Contract:
(Rs. In Figure) -------------------------------------------------------------------------------------------------
(Rs. In Words) -------------------------------------------------------------------------------------------------
S. Particulars of Item of Quantity Unit Rate Amount Amount Remarks
No. Work (in figure) (in words)
I II III IV V VI VII VIII
1.
2.
3.
4.
5.
6.
7.
8.
9.
10.
11.
12.
13.
14.
15.
Total Amount (Rs. In Figure)
Executive Engineer
….....................................
……………………………..
Page 77 of 78
SECTION 5
AGREEMENT FORM
AGREEMENT
This agreement, made on the _________________ day of ________________
between ___________________ (name and address of Employer) (hereinafter called " the
Employer) and____________________________________ (name and address of contractor)
hereinafter called "the Contractor" of the other part.
Whereas the Employer is desirous that the Contractor execute
________________________________________________________________ (name and
identification number of Contract) (hereinafter called "the Works") and the Employer has accepted
the Bid by the Contractor for the execution and completion of such Works and the remedying of
any defects therein, at a cost of Rs._________
______________________________________________________________
NOW THIS AGREEMENT WITNESSED as follows:
1. In this Agreement, words and expression shall have the same meanings as are respectively
assigned to them in the conditions of contract hereinafter referred to and they shall be
deemed to form and be read and construed as part of this Agreement.
2. In consideration of the payments to be made by the Employer to the Contractor as
hereinafter mentioned, the Contractor hereby covenants with the Employer to execute and
complete the Works and remedy any defects therein in conformity in all aspects with the
provisions of the contract.
3. The Employer hereby covenants to pay the Contractor in consideration of the execution
and completion of the Works and the remedying the defects wherein Contract Price or
such other sum as may become payable under the provisions of the Contract at the times
and in the manner prescribed by the Contract.
4. The following documents shall be deemed to form and be ready and construed as part of
this Agreement viz.
i. Letter of Acceptance
ii. Contractor's Bid
iii. Condition of Contract: General and Special
iv. Contract Data
v. Bid Data
vi. Drawings
vii. Bill of Quantities and
viii. Any other documents listed in the Contract Data as forming part of the Contract.
In witnessed whereof the parties there to have caused this Agreement to be executed the
day and year first before written.
The Common Seal of ____________________________________________ was hereunto
affixed in the presence of:
Signed, Sealed and Delivered by the said ____________________________
_________________________________________________________________ in the presence of:
Page 78 of 78
orutf,q rgs sTfu{idr
Tffiq qiBr+t tqr, qEqrtqr
"fr" ftfrl, trftq ng, ftfeq1q6 rrqq, .iTqrd
[email protected] I 0755 -2551398
1.
ftqq: aio. trrr fuilT gmr qffi Fifuil qq{ \r+futr z.ro ii risiltn erao (d+a
srrft-q( qrf d ftd) t
3. .b-R-.b-l 30.2 ii The security deposit may be replaced by equivalent amount of bank
guarantee (duly verified) or fixed deposit receipt from Scheduled Commercial Bank
assigned to the Employer (duly verified), with validity up to 3 (three) months beyond
the completion of Defect Liability Period/ extended Defect Liability Period. t|.6t
qdr
4. dR-6r 30.3 o) fr=dfud fo-qr qror t t
sffi riqilqq q-r srrftq-d sso- o-rqT d fuS t I qft qr ftfuEr utr;{ o-r
trwr€'nr
lpL)
rgs 3Tfu{iilr
qrftq qiBrot tcxr,
frqrg (q.s.)
g.m-+io
qfrftIfr:-
3l3q /zz/fr-10lil-qit /zozs dqrn, R-qi6 bS /os/zozs
10. GTfier"I ri*, il-frq qlfu+t +fl, qusET qE-dg{ qft fr{ srrq-d qd fr. 565
fufi-o. 03.05.2023 d ti{,f tt rA++ref gq Gr€{fi-- o-ffi ig nFo I
If the Routine Maintenance part of the contract is not carried out by the Contractor as
per this Contract, action under Clause 18 and 27 will be taken, and the Employer will be free
to get the routine Maintenance work carried out lrom another source and the amount required
for this work will be recovered from the amount of Performance Security available with tlie
Employer andlor from any amounts of the Contractor whatever is due along with additional
20Yo amotnt as penalty.
t0. gq efi=rrf,r, qrftur qlffi +qT, ffiq olqfd-q, .nqF, E-qti gq qqdgq, q.q I
2 2025_RES_
ffi rr+a B-alur gra-fia rra
qqr+d 3rrtFr< gg-{
405132 $-<t{ ,Jr$ur a<'h' 9.27 18540 2000 6 frr6 ceFr
or Bm p<tr
si4a-q6 r+a ffior q't{r +r-dtfr
3 2025_RES_
s-a&srurrff dsrq-d rsesr $At{
/t05133
rlr$sr oz ft-dr FdtT
tdt{ 9.27 18540 2000 616 cqq
2025_RES_
3ii4a-{r$ r+a Erqtor ii6r +o,
4
405135
trqrfl ara d"rq-d i?tsmr Fit{ r;d{ 9.27 18540 2000 6 416 csrq
Trfrur oz Bdr 5-<t{
Ji4a-qr$ gr+a ffiq Era ffr
2025_RES_
5
t105136 t-€t Ei.F rrra tiqr+a Ei+, 5atr 5dl{ 9.27 18540 2000 6 7116 C9FI
qrfrsr oz E-dr
f<t{
6. 2025_RES_ JrirraETSI rca F-atsr aiqft-ql m..
405137 oz, sitr Bm Fqt{ sit{ 9.27 18540 2000 6 416 CEFI
2025 RES
405LU
$irla_qr$ er+{ Batsr
,a-( Trmsr or Bm 5dtr
frqer 4-ftr{
a-(
9.27
9.27
18540
18540
2000
2000
6
6
A16
416
CEFI
qEFI
33 2025_RES_
/o5165 a.( qr$q Ol Bd{r f<t{
4-( 9.27 18540 2000 6 A16 CSFI
202s_RES_
4-( ,Irtrur 02 B-dr f;qt{
gier+qre fl'.ra F-dtqr it{-dtfl ,rrff
9.27 18540 2000 6 {16
l*"
40
trcs173
dvr+6 q56on, a-( ,Jrfrur 02 a-( 9.27 18540 2000 6 frr6 gerq
Bdr $-<t{
3ri?ra-ql& r+a E-at"r {rrrdrqrm
41. 2025_RES_
qrfr dqr+d aFF:u6nE, rq arfrur oz EB
445L74 9.27 18540 2000 6 7116 ceH
Bdr F<t{
:iizr+qr€f r+a B-aiq otcr 6i6fuqr
42. 202s_RES_
rrrfr dqr{d 6i6,ft-cl a.( qrfrur oz a-(
405L76 9.27 18540 2000 6 416 cqq
ft-dr F<t{
3dra-qr€t mra fusr grfrgu ara
43. 2025_RES_
dqrqa rqrq. a-( ,Jrmsr ot fraT a-( 9.27 18540 2000 6 ar6 geIII
405177
Fd{
gizr+qr€I r+a B-atq cnFEr qtrfi
44 2025_RES_
riqrq-d 4r{&, a-( ,Jrmq or Bar 4-( 9.27 18540 2000 6 416 gEFI
4o/5L78
v-<t{
sr{qrfuo rca fuor afr 3il5ar
2025_RES_
45. F6rfrsn E6 at. 5r, lrl3 q;qelrrTl ildT 4. O5 8r00 2000 4 A16 kdq
405180
EFfr f<t{ Bfr)
(Eqrq-o'
qB?rfrfr +-f,rs s-q (3rfrfrfr 6fi)
45. 2025_RES
405181
Mur qnsfrq anzft-o qa €itr 't3.42 2 5E40 2000 6 A16 ft-dq
qqn
qt{'- ({rRr drq f) 425.35
F
r- BftSI d.irf Rfuil {Kevpatesl}
r. f
eerqR q-fr q-6Rra 6rkdi6. to/o3/2ozs
2. Afuqr qtr{ 6-q 6.-ri or qFtsr
Fai6, rc/$/zozs Efi{r to;3o .r$
3. Ffuqr (t trqd +-ri or qrfrT
kaio' rc/o3/2o2s q_rrq ro:30 rS
4. Afuqr q-t q'q-d 6ri 61 3ifrfl
Eai+, zl/o3/zo?s sfiq t8:oo iri
s Bfufi il+AifiI fus ga-+ +r kaio zs/o3/zozs Efiq t2:3o rd
6. Efu{r futrq 3nw,nqd6r f{s g-f} }.qasrf, o,r4qrffT ?ifi rlrmq qiltrfl
t_qr isnq
f<t{ grrr Bqtkd frf,i+ +,t rffi ar&tr
2- frfa qr 3fra drtd fus r4r ori src a{rf,ts qre ffi ili (rtn}cil:_ 3rM
frEr$r-A
(l) frfud fttr{d trrrrq rrr qr ri;ftra nfifrs{q fiI {S{ 3Tqfrs qrrdr:rfrorS
(2) eFrsr rr{ TrR} 5q} roo/-6r ts qa +- 6{ 3rrf,t5 -rar grfu fg
s. F-qtET fi{ ,iiirfi sra fu+rorzur+orfr orqtilq, 6r4qrd-d ri*, ,rrfrur citrdl t-sr {rr,r $<t{ *
ordnr$-a rrq f i@ dr s-6-S t I
s. EfocrdFrt s) dla-6 ftdr+-fr) Fq t Eht$ $ (Rrtr 6r+aq d aqr n6t ori tr T-rs rmra-o
3iErdrtr .pdf rrr .rar (srt 3r{FK) €t rqa ori tr
z. Ef+cr+'r fi am snrerfa 3rq-dls f6't zrt sre (Frtr (Ffuqr rd * rEvnl (Frnq s€t qri ad
qr a ffirq 3frw ffi orqt*q, or{qrfid ?in, zrrsq qitrfr t-{r, drm F<t{ zoz ttdrfs a.ra
$dt{ f Btrttud Eaio q}d sritr
e. Efo<lrER Aff<r qfr€qt * snrr d-A fi $ ordqrd-d ?ii, {rfrur qifi_fir
$_qr {ir{rrr g-<t{ * +iu-6 6-1
6r{ n*rd 61 6r+ q-6R * aftTUr ,,rqeo-6'Fq t +r *i ilfi faiur 614 f 5qmrr 6ra Erfr fuur
{r,-rtr fir 5rrildrdr/qft-drFa fi dciq d eft rfr-eiT"fr r+do-a
g. Ffa-qrorr o,l rga-*r n ol *n d Ef+cm,-. h h_i *qqoq ilmr
soo rFT ErFr Fq{r{sr 6r+fq * {r iFir
ro. qot EfOar e-Frq 3@rykdt6 :. lti q-r-c nffia, 61a1
ft $Zx.tr #o mt ort+ ,
1r. ..r*nr nfrr ($rd.nF) 6r{q*d ii*, z,rsq qirra
*+ rifirrr. sdh *. qw f tq 6tfr irq, fos ilfi
o,{i h Edio' t t+ a5 fi srqfr a-o dq Ftdr qGq r
rz. Efa-qronzo-$ Enr q-do, 6r{ fi fun gq-6_Bro
Afrql fua trqd 6-rfi Ftrfil
rs. qt 6it &-qrr qdF'fr trFIfi m-d f qr&+r irrrqr
*c,Fdl1 d d ffi E_d Ero (r-6.& 614 h h_E
31il4-
3ffir Bfco u-qa a€l.6r artir raen q.d rm q-qd AfrEr{ f{F
ot A srtti
ra. FfusrdFrr fo'ifr efi fusrq fr *+, fr€s r€t qrtrtr qE
d_dr tsr qrqr qrar t d, d_.ifua
Efa-qr+nz&-Cr 6r Hfu<rzraev {rarr 6.r lAqr ara-rn
f
il
eiqi{ qr m-. aszotzztfu-ro zar.ci.t. s qrd
Edi6
zg.lt.zozz 3r{grt ffiur ord qr ra qfura S.trs.&.
&cR w iirr+ort
arq Fo-oruror t,il qq-5. t tq 6tn a.{11 srr5r
abnr
sa' rfr'('s'E. fi f f
ar*'r a*r {*,ra o.i cfdq f srrq-Frrq q{ B*d fqil qri qrd ,q-r.
iE
or qrila
fu-qT araT 3IM €trn derr riiifud &qR
h tqo t ,.esr. or Aqfir-{€R +-et*rz5rrara fu_q1
s+ Er€r6R 6) {6 qt'rrff rqld 6-r{r "67n,
il4, Bfuqr qqr 2.10 b. rqs sr, ure r5en Era-qmn rrc
iF<qv4 marr nqa 4€i' 6Ti q{ so,ooo/- qFer6,
6r€ ffi Tqrfud a6. 6'.{i q{ so,ooo/- $qi
qfr4r6 !d ilfi-fa 3r4-d 6r
Tfi ilfle q{ 2s,ooo/-.qE qfr.4T6 u-*r 61 *r+qrfi 6r
ar&frr {6 mqrff
fi ..{s* 3rtf*d rrtr d * bhc* 6r ,.{ilsr fuq'gd .Fr, ..,,a?r r'r (rno) aF tn{,
ote w ?
ga, Ffuqr 3IEiB-d fr qrtrfr,ffir
Rs. qo_s
-*cft
&,_qR a Fbfir
as. qA AfuEroR crr srr{r grqfu f
6rt Wt aO fa.qr orar d Ef+o sq{ ttBw z.ro 6r
t iiBor rs
rg€R $+{Ds 6r otffi fi
ar&rfir
ee. EfucI t
ddfud hrfi g *-lro,a w ue-a wm
or ffiq 3ifrq ati ara ilrnr
sz. EffEr fr f4ifr m s-6n 6r t'eftra qr qfisf,a qfi
ttdr rsor t il rfln 3ilffirtr w Eqr artqr
ffit qe-ar sflrrrn rt{ * fu artnr
c-6rRrd rfi
ra. frgR-opr 6r{ B ECd 6r sfrffd dfiqa q-ag q*
rtar nE-qr{ tr
eg. q*fia * tw nizr+qr€l r-q-d 6rd 6r rmiaa qrq
F}ar q-{arfod Fr
f,ifi )
or{crild ri*,
,Jrfrur qitc-6t C-dr
1. fuorg $19o,, dsrq-d a?i qrfrq fu+rs fuenrr, h;a{rqd r+a, ftid-q a-o siqrf,l
2. qtra a-6rdqmr, awqhr rqrfuq{ qeEr fr.fr.-+t
3. q-{q $m-{idr, rrr$q qiBdl 0-qr, orqtEq dTff a-s fuors r+a ntr Fm a.q. etqrflr
4. Uq sBziar,ar$ur qiftfi t-qr gat{ qffi{ orcl& $Etrr
5. o-ner, R-or f<trr
6. fl$Erur ?ii, rrrfrq qiB-& +qr 5<tr au-ro orqt@ Fekr
7. gw ordvma Jn6ft,R-dr dqr+d iatl
8. a.q. rnrdrq thqr ('Sfrqcn,32 gs{ a-rr,fuqf,rfi,fi.v+.$.w. rtvrat
9. qilfrr q.fr qr qwt F{t
[p-
?i*,
qimq qiB-Er t-4r